Transform Your Space

Last updated: January 2026

Information We Collect

We collect information you provide directly to us, such as when you:

• Contact us through our website or phone
• Request a consultation or quote
• Subscribe to our newsletter
• Participate in surveys or feedback

How We Use Your Information

We use the information we collect to:

• Provide interior design services
• Communicate with you about your projects
• Send you updates and marketing materials (with consent)
• Improve our services and website
• Comply with legal obligations

Information Sharing

We do not sell, trade, or otherwise transfer your personal information to third parties without your consent, except:

• To trusted service providers who assist in our operations
• When required by law or to protect our rights
• In connection with a business transfer or merger

Data Security

We implement appropriate security measures to protect your personal information against unauthorized access, alteration, disclosure, or destruction.

Your Rights

You have the right to:

• Access and update your personal information
• Request deletion of your data
• Opt-out of marketing communications
• File a complaint with regulatory authorities

Contact Us

If you have questions about this Privacy Policy, please contact us at:

Email: [email protected]
Phone: +1 (310) 864-2069

Last updated: January 2026

Acceptance of Terms

By accessing and using The Design Genius services, you accept and agree to be bound by the terms and provision of this agreement.

Services Description

The Design Genius provides professional interior design services including:

• Interior design consultation and planning
• Space planning and layout design
• Furniture and decor selection
• Project management and coordination
• Color consultation and material selection

Client Responsibilities

Clients agree to:

• Provide accurate and complete project information
• Make timely payments according to agreed terms
• Provide necessary access to project locations
• Communicate changes or concerns promptly
• Obtain necessary permits and approvals

Payment Terms

Payment terms will be specified in individual project contracts. Generally:

• Initial consultation fees are due upon booking
• Design fees are typically split into milestone payments
• Product purchases require deposits before ordering
• Final payments are due upon project completion

Intellectual Property

All design concepts, plans, and materials created by The Design Genius remain our intellectual property until full payment is received.

Limitation of Liability

The Design Genius shall not be liable for any indirect, incidental, special, or consequential damages arising from our services.

Termination

Either party may terminate services with written notice. Fees for completed work remain due upon termination.

Contact Information

For questions regarding these terms, contact us at:

Email: [email protected]
Phone: +1 (310) 864-2069

Last updated: January 2026

Professional Services Disclaimer

The Design Genius provides interior design services based on professional expertise and industry standards. However, we make no warranties or guarantees regarding:

• Specific outcomes or results
• Compatibility with existing structures or systems
• Third-party contractor performance
• Product availability or delivery timelines

Design Recommendations

All design recommendations are based on available information and professional judgment. Clients are responsible for:

• Verifying structural feasibility
• Obtaining necessary permits and approvals
• Ensuring compliance with local building codes
• Confirming product specifications and availability

Third-Party Services

We may recommend contractors, suppliers, or other service providers. The Design Genius is not responsible for the quality, timeliness, or performance of third-party services.

Photography and Marketing

Unless otherwise agreed, The Design Genius reserves the right to photograph completed projects for portfolio and marketing purposes.

Changes and Modifications

Project changes requested after design approval may result in additional fees and timeline adjustments. All changes must be documented in writing.

Force Majeure

The Design Genius shall not be liable for delays or failures in performance resulting from circumstances beyond our reasonable control, including but not limited to natural disasters, supply chain disruptions, or government regulations.

Consultation Disclaimer

Initial consultations provide general guidance only. Detailed recommendations require comprehensive design contracts and may involve additional fees.

Contact Us

For questions about this disclaimer, please contact:

Email: [email protected]
Phone: +1 (310) 864-2069